Renologist Pte. Ltd. v LONG SHIWEI KENNETH & Anor
Outcome
Claim dismissedI dismiss the claim in full.
Source: [2026] SGMC 69, Magistrate Court, decided 8 June 2026. Read directly from the judgment.
Key facts
| Court | Magistrate Court |
|---|---|
| Decided | |
| Judge | Sim Mei Ling |
| Charges / claim | Building and Construction Contracts |
| Outcome | Claim dismissed |
Source: [2026] SGMC 69, Magistrate Court, decided — eLitigation. Updated .
Catchwords
Practice Areas
Judges (1)
Case Significance
Renologist Pte. Ltd. v Long Shiwei Kenneth & Anor [2026] SGMC 69, decided by District Judge Sim Mei Ling on 8 June 2026 after hearings on 23 September and 12 November 2025 and 21 January and 4 May 2026, arose from Magistrate's Court Originating Claim No 4482 of 2024 concerning renovation works at a Housing and Development Board flat at 122 Potong Pasir Avenue 1, jointly owned by husband and wife Long Shiwei Kenneth and Koon Sze Yun, Vanessa. The claimant, Renologist Pte. Ltd., sued to recover allegedly outstanding payment under a renovation contract dated 14 June 2023 for $79,462.62 (the "June Contract"), while the defendants counterclaimed for the cost of completing the renovation and renting alternative premises during the delay. The judgment, addressing implied terms, delay, failure to complete, and repudiation in building and construction contracts, cites 10 Singapore authorities, the Civil Law Act and the Stamp Duties Act.
[2026] SGMC 69 explained
Renologist Pte. Ltd. v LONG SHIWEI KENNETH & Anor ([2026] SGMC 69) is a Singapore judgment decided by the Magistrate Court on 8 June 2026. It is categorised under Building and Construction Contracts. It is a recent decision; within this corpus no later judgment has cited it yet. This page summarises what the reported decision covers and links the primary sources — the full judgment, the statutes it cites, and the other cases it engages with — so the decision can be read in context. It is reference information, not legal advice, and it does not state the outcome or any holding beyond what the official judgment records.
What is [2026] SGMC 69 about?
Renologist Pte. Ltd. v LONG SHIWEI KENNETH & Anor ([2026] SGMC 69) is a Magistrate Court decision from 2026. Its published catchwords are “Building and Construction Contracts — Renovation contracts”, “Building and Construction Contracts — Terms — Implied terms”, “Building and Construction Contracts — Damages — Delay in completion”, and “Building and Construction Contracts — Damages — Failure to complete”, which indicate the subject matter the judgment addresses. The full reasoning and orders are in the judgment itself, linked below.
Which legislation does [2026] SGMC 69 consider?
The judgment refers to Civil Law Act (Cap 43) and Stamp Duties Act (Cap 312). The statutes cited are listed in full on this page, each linking to its primary text.
What dispute did the court resolve in Renologist Pte. Ltd. v Long Shiwei Kenneth & Anor [2026] SGMC 69?
In [2026] SGMC 69, District Judge Sim Mei Ling considered a renovation dispute over a Potong Pasir HDB flat, where claimant Renologist Pte. Ltd. sought outstanding payment under a $79,462.62 contract dated 14 June 2023, while defendants Long Shiwei Kenneth and Koon Sze Yun, Vanessa counterclaimed over delayed completion.
Statutes Cited
Cases Cited (10)
Referenced in
Statutes interpreted in this judgment
Legal concepts & references
Judgment
Read the full judgment on the official Singapore Courts portal.
Read on eLitigationSource: eLitigation ([2026] SGMC 69)